Selection Guide Price List 2013

SELECTION GUIDE
Price List 2013

Contents
Welcome to Gunnebo 3
Choosing a product 4

Eurosafe is an association of safe
Chubbsafes Elements 6 DataGuard NT 35 manufacturers in mainland Europe
established over 25 years ago. A
DataPlus 36 sister organisation, Eurosafe UK was
Air 8 2” Standard Quality Door 37 launched in March 2011 to
Water 9 Centurion Vault 38 represent the interests of British
safe makers, and the suppliers and
Earth 10 Centurion Door 39
installers of safes and security
Fire 11 Safe Deposit Lockers 40 containers
Notes 41 The primary objective of Eurosafe
UK is to restore confidence in
European standards for testing and
Chubbsafes 12 rating cash safes, security cabinets,
Churchill 42 document fire safes and computer
data safes.
Notes 14
Eurosafe UK will encourage insurers,
Counter Unit 15 Magpie Wall Safe 44
specifiers, buyers and users to
Epsilon 16 Domestic 45 choose cash safes tested and
ForceGuard 17 Vector 46 certified by the BRE/LPCB in the UK
Bulldog 400 47 or European test houses affiliated
AlphaPlus 18
with the European Fire & Security
Cobra 19 Sapphire 48 Group (EFSG) or those products
Zeta 20 Ruby 49 certified by the European Certifica-
Cobra Pro 21 Emerald 50 tion Board•Security (ECB•S).

DuoGuard 22 Notes 51 Member companies will campaign
to resist the lowering of security
ProGuard 22 standards by manufacturing and
Trident 24 supplying high quality, insurance
Sigma Deposit 26 approved products.
Rosengrens 52
Those companies specialising in
Omega Deposit 27
refurbishing used safes undertake
Cobra Deposit 28
Atlantic 54 to adhere strictly to BS7582: 2005
ProGuard DT 29 Code of practice for reconditioning
Sargasso 56
Profile NT 30 of used safes.
2000C Safe Deposit Lockers 57
Archive Cabinet 31 Member companies will be
Executive 32 encouraged to display the Eurosafe
logo as a symbol of quality and
Office 33
ethical standards.
Record Protection Cabinet 34 Terms & Conditions 58

Our Icons explained
P SELLER
TO

Fire protection for
Top selling product Key lock Burglary protection
paper documents

NEW

New product Fire protection for
Electronic lock Explosives protection
for 2013 data media

Approved by
The Association of
Insurance Surveyors

Welcome to the Gunnebo
Selection Guide 2013
Gunnebo is acknowledged as a worldwide leader in security products with a reputation of excellence in quality, reliability and
optimum security. This approach is reflected in the nature of the product range.
Each of the products have been designed, manufactured and tested to benefit you. The result is a flexible and customisable
range of safes, cabinets and vaults. Such a comprehensive product range means that finding a security solution is a simple
process. After all, we do want to solve your problem.

Our product range
Chubbsafes ...the premier cash & fire protection brand
Domestic users, retailers and banks are forever reviewing the secure storage of cash and
valuables within their environments. Faced with increasing threats to security, users are
constantly striving for products of the highest quality, reliability and technical specification.
Such products can be easily found within the Chubbsafes range. Choice doesn’t end once you
have selected the safe or cabinet that is perfect for you. Each solution can be customised with
a host of options (e.g. locking, fittings and deposit facilities) to meet your security needs.

Churchill Safes ...the premier underfloor safe brand
Churchill Safes are recognised as the leading brand for underfloor safes. Such success is based
upon understanding the security market and meeting customer needs. This commitment
and initiative is reflected in the Churchill Safes product range. Products vary from a small wall
safe to high security underfloor safes. Such a comprehensive range means that finding an
underfloor solution is a simple process.

Rosengrens ...the premier document protection brand
For every business protection of documentation is of paramount importance. Losing this
invaluable information can lead to a disastrous impact on the business.
Common outcomes include the loss of clients and a decline in capacity to attain new business.
With the Rosengrens product range you are sure to find a flexible and secure solution.
Combining unique design and innovative features, each safe or cabinet ensures that your
documents are securely protected to the highest standards.

Selection Guide 2013 3

CHOOSING A PRODUCT
IS SIMPLE
Picking a new safe for the home or business can be a struggle, especially
when you don’t know where to start.
With Gunnebo, you can be assured that we will guide you carefully
through the selection process, a process which begins by identifying
your security objectives. Once complete, a number of suitable security
solutions will be offered and comprehensive support given regarding
the delivery and installation of the safe.
All in all, Gunnebo aims to make sure the selection process is a flexible,
simple and thorough one.

Planning, Delivery & Installation
The complete service
Once you have selected a safe or cabinet, Gunnebo can offer you a
comprehensive installation survey (for certain products only). Gunnebo
will then agree with you a flexible installation schedule. The flexibility
of the installation process is evidence of Gunnebo’s commitment
towards ensuring the cost and time efficient completion of your purchase.
Gunnebo products are delivered and installed by trained Gunnebo
installers. Whatever the delivery environment (e.g. large bank or small
office), you can be assured that the installers will take the greatest care.
We are also focused on making sure the service on offer is achievable,
to the highest standards of workmanship and is promptly completed
within the contracted timescales.

CHOOSING the right product
To find out which product is most suitable for your security requirements you
need to answer the following questions:
1. hat do you want to protect?
W
Cash, Valuables, Documents or Data media
Customisation
2. hat is the volume or size that you want to protect?
W
Dependant on the product grade or size, most safes or cabinets can have a
Having done this you can either choose from BRE (Burglary Resistant different lock (e.g. electronic), deposit option (e.g. front facing drawer trap) or
Equipment) or FRE (Fire Resistant Equipment) products. The BRE range fitting (e.g. cupboard) to meet your customer requirements. For example, the
includes safes, cabinets and vaults designed to protect cash and valuables. DataPlus can include pullout drawers so that it can hold more CDs, DVDs or
Available in differing sizes and specifications these products offer optimum diskettes.
protection for up to £150,000 or £1,500,000 in valuables.
For further details and technical information regarding customisation please
The FRE range includes files and cabinets designed to protect against fire. feel free to contact Gunnebo or your local authorised dealer. As always,
You can either protect data media or documents and in some cases a mixture Gunnebo will endeavour to provide a customisation solution which meets
of both. These products are rated according to their level of fire protection. your expectations.

Cash Rating Locking Options
Cash Rating is “The amount an insurance company will cover in a safe/ As mentioned, Gunnebo can customise your safe or cabinet with a different
cabinet overnight.“ lock.
The actual amount of cover can vary between insurance companies and Our comprehensive lock range includes the latest industry locks which offer a
locations and may be different to the manufacturer’s recommended rating. If wide range of features. So whether it be the “mechanical combination” lock
this is important to you, you should check what cover your insurance company or a more hi-tech electronic solution, Gunnebo are sure to have a lock which
will offer. will meet your security needs. We have explained the key terms associated
As a general rule, this rating is multiplied by a factor of 10 for jewellery. Hence, with locks below.
a Duoguard Grade 0 with a cash rating of £6,000 will store jewellery in If you have any additional questions please contact Gunnebo or your local
domestic circumstances worth up to £60,000. Gunnebo Authorised Dealer.

Fire Protection Definitions
Measured through tests carried out by Independent testing authorities. Key Lock: A manual key operated lock.
“The longer the period in minutes, the greater the fire resistance offered. The Mechanical Combination: A mechanical keyless dial lock with a
critical temperature before paper documents combust is 177°C. Whereas, changeable combination.
data media is damaged at temperatures over 52°C or humidity over 85%.”
Electronic Lock: An electronically operated keypad lock with a
Care should be taken to ensure that the test certificate held by the changeable combination.
equipment is applicable to modern media i.e a DIS label.
Manager Mode: Allows one user to control the functions of other
combination holders.
Testing Number of Users: The number of users able to program in their own
To provide the appropriate level of protection for our products, Gunnebo access code.
ensures that they are tested against the latest industry standards. These Duress Feature: It is possible for an alarm engineer to link the lock
standards vary according to whether you want to protect data media or into a monitored alarm system. It is then possible, by a given
documents. This is because the temperature at which data media (e.g. 52 °C) procedure, to operate the lock, open the safe and silently signal to the
and documents (e.g. 177 °C) deteriorate differs according to the item protected. monitoring station that this is being done under duress.
In order to fully protect data media, industry standards indicate that products Time Delay: This feature allows for a pre-set delay between operating
should carry ECB•S EN 1047-1 or NT Fire 017 60/120 DIS. the lock and being able to open the safe. The operation may vary
The ECB•S test monitors the internal temperature of the data cabinet until it between lock types.
has completely cooled down during the “soak-out” period. Assessing products Time Lock: Time lock allows the user to set periods during which the
during this period is essential since internal temperatures can peak up to 6 to lock may be operated, e.g. during business hours only. The options
8 hours after a fire has been extinguished. Such a test ensures that all products available will vary between locks.
are comprehensively tested and upon passing, will fully protect your data media
Audit Trail: The lock is able to give a report (it will vary in detail from
for the 60 or 120 minutes stated.
model to model) of usage and may show times of operation, codes
For document protection all products must have an appropriate industry used and operations performed.
standard 60 minute paper certificate as a minimum.
Dual Control: Allows two users to enter their details before any
UL72-Class 350, ECB•S EN 1047-1 or NT Fire 017 are acceptable standards for operation can be performed.
paper document protection.


Chubbsafes
Elements

Protect your valuables.

Chubbsafes Elements is a new family of safes designed for the simple
and effective protection of your cash and valuables.

With four ranges – Air, Water, Earth and Fire – and a choice of sizes,
you can be sure to find a safe which suits you.

Visit www.chubbsafeselements.com to find out more.
Scan the QR-code with your smartphone for quick access to the site!

@Chubbsafes

6 Selection Guide 2013

Protect the planet.
Each range in the Elements family is linked to an environmental project,
part of Chubbsafes’ commitment to help protect the world around us.

To tie-in with the Air range, Chubbsafes is making an annual
donation to Carbon Clear to help reduce the emission of harmful
greenhouse gases.
Read more at www.carbon-clear.com

To tie-in with the Water range, Chubbsafes is making an annual
donation to WaterAid to help the world’s poorest communities
access safe water.
Read more at www.wateraid.org

To tie-in with the Earth range, Chubbsafes is making an annual
donation to TREE AID to help fight poverty in Africa through the
planting of trees.
Read more at www.treeaid.org.uk

To tie-in with the Fire range, Chubbsafes is making an annual
donation to Cool Earth to help protect the world’s endangered
rain forests from destruction.
Read more at www.coolearth.org


NEW

air
£1000 cash rating

Key Features
• ompact safe for the home or office
C
• ecommended cash rating of £1000
R Model above is Air Laptop

• uitable for storage of valuables such as jewellery and cameras
S View the product videos on
our YouTube channel
• hoice of key lock or electronic lock
C www.youtube.com/chubbsafes

• teel door and body with dual, plated steel moving boltwork
S
• wo sizes available – 9 and 16 litres – as well as special models for hotels and laptop storage
T
• emovable shelf available for Air 15
R

Aldridge
External (mm) Internal (mm) Volume Weight Cash Retail Delivery
Model Product
Height Width Depth* Height Width Depth (litres) (kg) Rating Price Price
Code
Key Lock

Air 10K 200 310 200 190 300 150 9 8 £1,000 £69 £21 L18857

Air 15K 250 350 250 240 340 200 16 11 £1,000 £82 £21 L18859

Electronic Lock

Air 10E 200 310 200 190 300 150 9 8 £1,000 £89 £21 L18858

Air 15E 250 350 250 240 340 200 16 11 £1,000 £110 £21 L18860

Air: Laptop 200 430 350 190 420 300 24 13 £1,000 £126 £21 L18861

Air: Hotel** 200 430 350 190 420 300 24 13 £1,000 £189 £21 L18862

* Lock and handle projection 35mm
** CEU unit and software available at an additional cost
BRE – Burglary Resistant Equipment

Available through our preferred distributor – Aldridge Security
Tel: 08444 125 101 (Landline), 03444 125101 (Mobile), Ireland 01 647 0048
E-Mail: sales@aldridgesecurity.co.uk
Web: www.aldridgesecurity.co.uk
Fax: London 0800 137 933, Manchester 0800 137 932, Ireland 01 647 0049

For your safe spares please contact Gunnebo Safe Spares on 07919 015975 or 01902 271378
8 Selection Guide 2013 You can now buy spares online www.safespares.co.uk

NEW EN
14450 EN 1300 EN 1300

S1

water
£2000 cash rating

Key Features
C
• ash rating of £2000
C
Model above is Water 40E
• ertified by ECB•S according to EN 14450 Level S1 for burglary protection
C View the product videos on
our YouTube channel
• uitable for storage of valuables such as jewellery, cameras or other valuable equipment
S www.youtube.com/chubbsafes

C
• teel door and body with reinforced bolts and anti-drilling plate for extra protection
S
• our sizes available – capacity from 29 to 51 litres
F
• ne removable shelf as standard
O
• nterior LED light on electronic lock models
I

Drop off Delivery Aldridge
External (mm) Internal (mm) Volume Weight Cash Retail
Model Delivery Position Product
Height Width Depth* Height Width Depth (litres) (kg) Rating Price
Price** Price Code
Key Lock

Water 30K 275 375 350 269 369 294 29 31 £2,000 £204 £21 £115 L18863

Water 40K 375 375 350 369 369 294 40 36 £2,000 £243 £58 £115 L18865

Water 50-1K 375 475 350 369 469 294 51 43 £2,000 £308 £58 £115 L18867

Water 50-2K 475 375 350 469 369 294 51 43 £2,000 £344 £58 £115 L18869

Electronic Lock

Water 30E 275 375 350 269 369 294 29 31 £2,000 £348 £21 £115 L18864

Water 40E 375 375 350 369 369 294 40 36 £2,000 £419 £58 £115 L18866

Water 50-1E 375 475 350 369 469 294 51 43 £2,000 £459 £58 £115 L18868

Water 50-2E 475 375 350 469 369 294 51 43 £2,000 £512 £58 £115 L18870

** Drop off delivery to a kerbside location


You can now buy spares online www.safespares.co.uk Selection Guide 2013 9

NEW EN
14450 EN 1300 EN 1300

S2

earth
£4000 cash rating

Key Features
C
Model above is Earth 15E
• ash rating of £4000
C View the product videos on
our YouTube channel
• ertified by ECB•S according to EN 14450 Level S2 for burglary protection
C www.youtube.com/chubbsafes

C
• ody consists of two steel plates filled in-between with a fire-retardant material
B
• our sizes available – 15, 38, 54 and 76 litres
F
• ne removable shelf as standard
O
• nterior LED light on electronic lock models
I

Model Delivery Position Product
Price** Price Code
Key Lock

Earth 15K 300 370 350 210 280 250 15 38 £4,000 £215 £58 £115 L18871

Earth 40K 440 450 400 350 360 300 38 60 £4,000 £344 £58 £115 L18873

Earth 55K 590 450 400 500 360 300 54 76 £4,000 £401 £58 £115 L18875

Earth 75K 790 450 400 700 360 300 76 92 £4,000 £466 £58 £115 L18877

Electronic Lock

Earth 15E 300 370 350 210 280 250 15 38 £4,000 £369 £58 £115 L18872

Earth 40E 440 450 400 350 360 300 38 60 £4,000 £495 £58 £115 L18874

Earth 55E 590 450 400 500 360 300 54 76 £4,000 £644 £58 £115 L18876

Earth 75E 790 450 400 700 360 300 76 92 £4,000 £666 £58 £115 L18878




NEW EN
14450
EN
15659 EN 1300 EN 1300

30 s
S2 m in ute

fire
£4000 cash rating

Key Features
•
Combined fire and burglary protection in one safe
•
Perfect for the protection of cash and valuables as well as passports, property records,
Model above is Fire 25E
legal papers and other important documents
View the product videos on
•
Certified by ECB•S for 30 minutes fire-resistance (EN 15659, 30 P) our YouTube channel
www.youtube.com/chubbsafes
•
Certified by ECB•S for Level S2 burglary protection (EN 14450)
•
Choice of key lock or electronic lock
•
Four sizes available – 18, 26, 31 and 51 litres

Fire Drop off Delivery Aldridge
Model Rating Delivery Position Product
(mins) Price** Price Code
Key Lock

Fire 20K 315 445 440 185 334 290 18 52 30 £4,000 £246 £58 £115 L18962

Fire 25K 490 360 440 360 249 290 26 62 30 £4,000 £297 £58 £115 L18963

Fire 30K 460 440 440 330 329 290 31 68 30 £4,000 £378 £58 £115 L18964

Fire 50K 670 440 440 540 329 290 51 91 30 £4,000 £450 £58 £115 L18965

Electronic Lock

Fire 20E 315 445 440 185 334 290 18 52 30 £4,000 £425 £58 £115 L18958

Fire 25E 490 360 440 360 249 290 26 62 30 £4,000 £461 £58 £115 L18959

Fire 30E 460 440 440 330 329 290 31 68 30 £4,000 £544 £58 £115 L18960

Fire 50E 670 440 440 540 329 290 51 91 30 £4,000 £727 £58 £115 L18961





Selection Guide Price List 2013

...the premier cash fire protection brand

Domestic users, retailers and banks are forever reviewing the secure
storage of cash and valuables within their environments. Faced with
increasing threats to security, users are constantly striving for products of
the highest quality, reliability and technical specification. Such products
can be easily found within the Chubbsafes range. Choice doesn’t end once
you have selected the safe or cabinet that is perfect for you. Each solution
can be customised with a host of options (e.g. locking, fittings and deposit
facilities) to meet your security needs.

www.chubbsafes.com
Follow us on Twitter @Chubbsafes

Notes
Notes


Counter Unit
Burglary protection for banknotes

Key Features
• Helps prevent banknote theft at cash tills
• Mounted under the counter to securely store and protect banknotes
• Easy-to-reach deposit slot
• Stores up to 350 banknotes
• Two key locks – one to open storage unit and one to release from counter for easier emptying
• Solid sheet steel construction

Note Aldridge
External dimensions (mm) Weight Retail Delivery
Model Capacity Product
Height Width Depth (kg) Price Price
(qty) Code
CU-350 235 105 190 350 2,4 £60 £21 L18856




NEW

Epsilon
Burglary protection for keys
Model above is
Size 3

Key Features
• Door is made of 6mm steel
• Body is made of 2mm steel
• 16mm diameter steel bolts operating in three directions secure the door
• Epsilon cabinets have a key deposit feature on the side of the safe which allows keys to be securely deposited inside.
Once inside, an anti-fishing plate prevents their removal
• Keys are stored on key hooks which, thanks to internal ladder racking, can be adjusted to accommodate keys of different lengths
• Epsilon comes in two lock options – double bitted 8 lever key lock or programmable electronic lock
• four point anchoring kit is supplied so the safe can be securely rear fixed to resist unauthorised removal once installed
A

Aldridge
External dimensions (mm) Internal dimensions (mm) Volume Weight Key Retail Delivery
Model Product
Height Width Depth* Height Width Depth (litres) (kg) Capacity Price Price
Code
Key Lock

Size 1 500 400 130 496 396 77 16 18 88 £365 £21 L21769

Size 2 500 400 180 496 396 127 25 23.5 128 £455 £21 L21770

Size 3 500 400 200 496 396 147 29 24 168 £485 £21 L21771

Size 4 500 400 250 496 396 197 39 27.5 208 £539 £21 L21772

Electronic Lock

Size 1 500 400 130 496 396 77 16 18 88 £405 £21 L21773

Size 2 500 400 180 496 396 127 25 23.5 128 £495 £21 L21774

Size 3 500 400 200 496 396 147 29 24 168 £525 £21 L21775

Size 4 500 400 250 496 396 197 39 27.5 208 £579 £21 L21776

* Projection of handle is 5mm



EN 1300

ForceGuard
£2,000 cash rating
Model above is
Size 4

Key Features
• Multipurpose cabinet for the protection of cash and valuables (e.g. audio-visual equipment and mobile phones)
• Recommended cash rating of £2,000
• Single wall body constructed from 3mm steel plate. Doors secured by 3-way moving boltwork with a fixed dogging bar
• Secured by a double bitted high security key lock as standard
• Supplied with removable shelves as standard
• Cabinet must be fixed to the floor via the anchoring points in the base
• Available in four sizes
• Finished in a light grey colour

Fittings Delivery
Number External dimensions (mm) Internal dimensions (mm) Volume Weight Cash Retail
Model Locking (Supplied) Base Fixing
of doors Height Width Depth* Height Width Depth (litres) (kg) Rating Price
Shelf Price
Size 1 1 1000 600 450 975 575 400 236 80 Key Lock 3 £2,000 £913 £157

Size 2 2 1500 900 450 1475 875 400 534 140 Key Lock 4 £2,000 £1,254 £183

Size 3 2 1900 900 450 1875 875 400 680 225 Key Lock 4 £2,000 £1,597 £222

Size 4 2 1900 1220 450 1875 1195 400 920 275 Key Lock 4 £2,000 £1,825 £347




NEW

AlphaPlus
Model above is
£3,000 cash rating Size 2

Key Features
• Suitable for the home and commercial environments
• Constructed with a 6mm steel door
• Double walled construction consisting of 3mm outer steel, 2mm steel inner body with an overall wall thickness of 40mm.
Cavity between the inner and outer body is filled in between with a fire retardant material
• Hardened steel plates protect the boltwork and lock against drilling
• 25mm diameter steel bolts secure the door
• Available with double bitted 8 lever key lock or Chubbsafes own programmable electronic lock
• Override key supplied with electronic version
• Fixing kit allows DIY base or rear fixing of safe
• Supplied with removable shelf as standard

Fittings Drop off Delivery Aldridge
External dimensions (mm) Internal dimensions (mm) Volume Weight Cash Retail
Model (Supplied) Delivery Position Product
Shelf Price** Price Code
Key Lock

Size 2 270 350 345 190 270 252 13 28 1 £3,000 £169 £21 £115 L21750

Size 3 320 440 395 240 360 302 26 45 1 £3,000 £224 £58 £115 L21752

Size 6 610 460 395 530 380 302 60 73 1 £3,000 £340 £58 £115 L21754

Electronic Lock

Size 2 270 350 345 190 270 252 13 28 1 £3,000 £203 £21 £115 L21751

Size 3 320 440 395 240 360 302 26 45 1 £3,000 £252 £58 £115 L21753

Size 6 610 460 395 530 380 302 60 73 1 £3,000 £382 £58 £115 L21755




EN
14450 JIS S1037

30
S2 m in utes

Cobra
£4,000 cash rating Model above is
Size 2

Key Features
• A quality cash safe constructed using highly reliable materials
• Tested to European standard EN 14450, level S2
• Offers 30 minutes fire protection for documents. Tested in accordance to JIS S1037
• Manufactured in accordance with Quality Management System ISO 9001:2008
• Supplied with fittings (see table below)
• Supplied as standard with a key lock and mechanical combination lock
• Available in five sizes

Internal Fire Delivery
External dimensions (mm) Internal dimensions (mm) Weight Fittings Cash Retail
Model Volume Locking Rating Base Fixing
Height Width Depth* Height Width Depth (kg) Shelf Drawer Rating Price
(litres) (mins) Price
Size 1 400 500 475 270 370 320 32 185 Key KC N/A N/A 30 £4,000 £715 £179

Size 2 600 500 475 470 370 320 56 225 Key KC 1 N/A 30 £4,000 £784 £195

Size 3 750 500 475 620 370 320 73 265 Key KC 1 1 30 £4,000 £910 £212

Size 4 750 630 575 620 500 420 130 373 Key KC 1 1 30 £4,000 £1,101 £258

Size 5 980 630 575 850 500 420 179 467 Key KC 1 1 30 £4,000 £1,329 £290


Additional
Lock
Cut Key

All models £49

Model Capsules (per 10) Capsule Deposit Envelope Slot

Size 1 N/A N/A £476

Size 2 £20 £406 £476

Size 3 £20 £406 £476

Size 4 £20 £406 £476

Size 5 £20 £406 £476

Maximum deposit size:
1. Envelope Slot
25mm x 180mm (H x W)


NEW 1143-1 EN 1300 EN 1300
EN

Grade 0

Zeta
Model above is
£6,000 cash rating 25E

Key Features
• Cash safe for the home and commercial environments
• Tested and certified to European Standard EN 1143-1
• Secured by a double bitted key lock or user-friendly electronic lock. Both locks
comply to EN 1300
• Supplied with a shelf as standard
• Fixing kit allows DIY securing of safe to floor and/or wall

Fittings Drop off Delivery Aldridge
Model (Supplied) Delivery Base Fixing Product
Height Width Depth Height Width Depth (litres) (kg) Rating Price
Shelf Price* Price Code
Key Lock

15K 280 370 350 190 280 250 13 38 1 £6,000 £424 £58 £115 L21756

25K 330 450 400 240 360 300 26 53 1 £6,000 £523 £58 £139 L21758

Electronic Lock

15E 280 370 350 190 280 250 13 38 1 £6,000 £598 £58 £115 L21757

25E 330 450 400 240 360 300 26 53 1 £6,000 £696 £58 £139 L21759

* Drop off delivery to a kerbside location



NEW EN
1143-1 EN 1300 EN 1300

G ra d e I

Cobra Pro
£10,000 cash rating
Model above is Size 3K
View the product videos on
our YouTube channel
www.youtube.com/chubbsafes
Key Features
• Grade I burglary protection certified by ECB•S in accordance with the European standard, EN 1143-1
• Fitted with either a Class A key lock or a Class B high-security electronic lock, approved in accordance with
European standard EN 1300
• Safes equipped with an electronic lock also have an LED light inside
• Ergonomic, soft-touch handle
• Interior ladder racking system for flexible positioning of multiple shelves. One shelf is supplied as standard
• Thinner walls for increased internal capacity

Drop off Delivery
Model Delivery Base Fixing
Price** Price
Key Lock

Size 1K 390 500 440 310 420 300 40 125 £10,000 £836 £58 £179

Size 2K 650 500 510 570 420 370 88 203 £10,000 £977 £58 £195

Size 3K 800 600 550 720 520 410 153 270 £10,000 £1,121 £58 £212

Electronic Lock

Size 1E 390 500 440 310 420 300 40 125 £10,000 £1,028 £58 £179

Size 2E 650 500 510 570 420 370 88 203 £10,000 £1,204 £58 £195

Size 3E 800 600 550 720 520 410 153 270 £10,000 £1,351 £58 £212

* Handle projection 56mm

Fitting Shelf

Size 2 £23

Size 3 £31


TO
P SELLER EN
1143-1
EN
1047-1 EN 1300 EN 1300

Gr 60
a d e 0 − III m in utes

DuoGuard G0, GI ProGuard GII, GIII
£6,000 to £35,000 cash rating (Grade 0, I, II, III)
Model above is
Model 150

Key Features
• Constructed using Chubbsafes revolutionary new lightweight barrier material
• Recommended cash rating of up to £35,000 (Grade III)
• Tested and certified by the ECB•S to European standard EN 1143-1
• Offers 60 minutes fire protection for documents (Grades 0–I only). Tested and certified to European Standard EN 1047-1 Class S 60 P
• Supplied with a high security EN 1300 approved class A key lock or class B electronic lock
• Can be customised with locking options and fitting options (e.g. shelf, drawer)
• New modern design with a contemporary two tone satin finish
• Available in a comprehensive range of product sizes

Internal Fittings Fire Retail Price Delivery
External dimensions (mm) Internal dimensions (mm) Weight Cash
Model Volume (Supplied) Rating Base Fixing
Height Width Depth* Height Width Depth (kg) Rating Key Lock Electronic
(litres) Shelf (mins) Price
Grade 0 40 435 500 456 335 400 295 40 90 1 60 £6,000 £871 £1,119 £193
60 530 500 521 430 400 360 62 115 1 60 £6,000 £1,095 £1,350 £212
110 690 600 561 590 500 386 114 161 2 60 £6,000 £1,302 £1,541 £227
150 875 600 561 775 500 386 150 196 2 60 £6,000 £1,570 £1,803 £235
200 1150 600 561 1050 500 386 203 243 2 60 £6,000 £1,821 £2,055 £270
300 1600 600 561 1500 500 386 290 322 3 60 £6,000 £2,279 £2,498 £316
350 1600 675 585 1500 575 410 354 352 3 60 £6,000 £2,444 £2,698 £350
450 1850 675 615 1750 575 440 443 415 4 60 £6,000 £2,795 £3,037 £352
Grade I 40 435 500 456 335 400 295 40 90 1 60 £10,000 £914 £1,168 £193

60 530 500 521 430 400 360 62 115 1 60 £10,000 £1,137 £1,391 £212
110 690 600 561 590 500 386 114 161 2 60 £10,000 £1,633 £1,866 £227
150 875 600 561 775 500 386 150 196 2 60 £10,000 £1,786 £2,026 £235
200 1150 600 561 1050 500 386 203 243 2 60 £10,000 £2,055 £2,294 £270
300 1600 600 561 1500 500 386 290 322 3 60 £10,000 £2,504 £2,765 £316
350 1600 675 585 1500 575 410 354 352 3 60 £10,000 £2,795 £3,042 £350
450 1850 675 615 1750 575 440 443 415 4 60 £10,000 £3,261 £3,421 £352
Grade II 60 530 500 521 430 400 360 62 234 1 N/A £17,500 £1,678 £1,912 £207
110 690 600 561 590 500 386 114 334 2 N/A £17,500 £2,167 £2,400 £216
150 875 600 561 775 500 386 150 402 2 N/A £17,500 £2,505 £2,739 £245
200 1150 600 561 1050 500 386 203 501 2 N/A £17,500 £2,779 £3,013 £330
300 1600 600 561 1500 500 386 290 744 3 N/A £17,500 £3,533 £3,767 £396
350 1600 675 585 1500 575 410 354 846 3 N/A £17,500 £3,943 £4,177 £461
Grade III 110 690 600 561 600 510 396 121 315 2 N/A £35,000 £2,742 £3,074 £216
150 875 600 561 785 510 396 159 377 2 N/A £35,000 £3,012 £3,344 £245
200 1150 600 561 1060 510 396 214 486 2 N/A £35,000 £3,499 £3,831 £330
300 1600 600 561 1510 510 396 305 655 3 N/A £35,000 £4,049 £4,381 £396
350 1600 675 585 1510 585 420 371 703 3 N/A £35,000 £4,907 £5,239 £461
450 1850 675 616 1760 585 451 463 813 4 N/A £35,000 £5,234 £5,566 £495



Fitting Shelf Full width drawer Lockable cupboard

All Grades Size 40 £21 N/A N/A
Size 60 £23 N/A N/A
Size 110–300 £31 £241 £254
Size 350 £36 £274 £285
Size 450 £42 £314 £314

Additional Mechanical Two Key and Two Key and
Lock Electronic
Cut Key Combination Key Locks Combination Combinations Electronic
All Grades* All sizes £59 £141 £155 £237 £265 £333 £346

* Dual locking not available on Grade II size 60

Model Capsules (per 10) Capsule Deposit Envelope Slot

All Grades Size 40 N/A N/A N/A
Size 60 N/A N/A N/A

Size 110–300 £20 £386 £453
Size 350 £20 £386 £453
Size 450 £20 £386 £453

Maximum deposit size:
1. Envelope Slot
25mm x 180mm (H x W)


EN
1143-1
NT
Fire 017
EN
1143-1 EN 1300 EN 1300

Gr ra
a d e I V−VI 60
G

d e IV−VI E
X

s
m in ute

Trident
From £60,000 to £150,000 cash protection, fire protection
and explosives protection (Grades IV, V, VI)

Model above is
Key Features Model 600

• Recommended cash rating of up to £150,000 (Grade VI)
• Tested and certified to the highest industry standards for burglary, fire and explosives protection
• A series of EN 1300 certified key locks, combination locks and electronic locks are available to choose from
• Full access of contents at 90° door opening
• Available in right or left hinge versions
• Can be customised with locking options and fitting options (e.g. shelf, drawer)
• New modern design in a contemporary black finish
• Available in 7 sizes for each grade

Internal Fittings Total depth Total width Fire Delivery
External dimensions (mm) Internal dimensions (mm) Weight Cash Retail
Model Volume Locking (Supplied) with door(s) with door(s) at Rating Base Fixing
Height Width Depth* Height Width Depth (kg) Rating Price
(litres) Shelf at 90° (mm) 180˚ (mm) (mins) Price
Grade IV Size 110 790 730 560 620 560 320 111 560 Two Key Locks 2 1205 1420 60 £60,000 £3,419 £299
Size 170 920 730 640 750 560 400 168 695 Two Key Locks 2 1285 1420 60 £60,000 £4,217 £333

Size 910 1850 1250 740 1680 1080 500 907 2060 Two Key Locks 4 1385 2568 60 £60,000 £12,259 POA
Grade V Size 110 790 730 560 620 560 320 111 595 Two Key Locks 2 1205 1420 60 £100,000 £4,560 £299
Grade VI Size 110 790 730 560 620 560 320 111 635 Two Key Locks 2 1205 1420 60 £150,000 £7,019 £333

* Projection of handle is 63mm. Depth of hinge is not included in these measurements


Additional Key and Two Key and
Lock
Cut Key Combination Combinations Electronic

All Grades All sizes £59 £237 £265 £346

Fitting Shelf Reinforced Shelf Full Width Drawer

All Grades Size 110 £37 POA N/A

Size 170 £37 POA N/A

Size 210 £37 POA £308

Size 310 £37 POA £308

Size 420 £37 POA £308

Size 600 £49 POA £354

Size 910 £80 POA POA



NEW

Sigma Deposit
Model above is
£1,000 cash rating Size 2E

Key Features
• Deposit cash safe allows individuals to securely deposit cash, cheques and vouchers
• Deposit slot (170mm x 16mm) fitted with an anti-fishing device to prevent unauthorised removal of deposited items
• Constructed with an 8mm steel door and 3mm steel body. Hardened steel plates protect boltwork and lock against drilling
• Available with double bitted key lock or electronic lock (sizes 2 3 only)
• Override key supplied with electronic version
• Fixing kit allows DIY base or rear fixing of safe

Aldridge
External dimensions (mm) Internal dimensions (mm) Volume Weight Cash Retail Delivery
Model Product
Height Width Depth* Height Width Depth (litres) (kg) Rating Price Price
Code
Key Lock

Size 1 305 375 350 299 369 289 32 24 £1,000 £152 £21 L21760

Size 2 375 375 350 369 369 289 39 27 £1,000 £182 £21 L21761

Size 3 475 375 350 469 369 289 50 31 £1,000 £222 £21 L21763

Electronic Lock

Size 2 375 375 350 369 369 289 39 27 £1,000 £215 £21 L21762

Size 3 475 375 350 469 369 289 50 31 £1,000 £255 £21 L21764

* Electronic lock projection is 35mm



NEW

Omega Deposit
Model above is
£3,000 cash rating Size 1

Key Features
• quality cash safe for the deposit of cash and valuables
A
• Door is made from 10mm steel and body is made of 6mm steel
• The door is secured by a three way moving bolt mechanism
• anti-fishing device prevents unauthorised removal of deposited items
An
• Available with double bitted key lock or electronic lock
• Deposit opening measures 80mm x 265mm x 220mm (hxwxd)

Model Delivery Base Fixing Product
Height Width Depth Height Width Depth (litres) (kg) Rating Price
Price* Price Code
Key Lock

Size 1 455 340 380 212 328 308 24 54 £3,000 £255 £58 £139 L21765

Size 2 698 340 380 455 328 308 48 75 £3,000 £370 £58 £153 L21766

Electronic Lock

Size 1 455 340 380 212 328 308 24 54 £3,000 £299 £58 £139 L21767

Size 2 698 340 380 455 328 308 48 75 £3,000 £433 £58 £153 L21768





Cobra Deposit
£4,000 cash rating
Model shown is
Size 5
Key Features
• A quality deposit cash safe constructed using highly reliable materials
• Deposit feature allows multiple users to constantly deposit cash and
valuables securely whilst the main body of the safe remains locked
• Deposit drawer secured by double bitted key lock (front-facing only)
• Maximum deposit size approx 60mm x 240mm x 120mm
• Available in three sizes

Internal Delivery
Model Volume Locking Base Fixing
Height Width Depth* Height Width Depth (kg) Supplied Rating Price
(litres)** Price
Size 2 854 500 475 470 370 320 56 325 Key KC Empty £4,000 £1,282 £214

Size 3 1004 500 475 620 370 320 73 365 Key KC Empty £4,000 £1,393 £231***

Size 5 1234 630 575 850 500 420 179 567 Key KC Empty £4,000 £1,807 £308***

** Internal volume does not include allowance for anti-fishing devices
*** Sizes 3 5 made to order – extended lead time

Additional
Lock
Cut Key

All models £49


EN
1143-2 D EN 1300

Gr
a d e I − II

ProGuard DT GI GII
Up to £17,500 cash rating (Grade I, II)
Model shown is
Size 110
Key Features
• Constructed using Chubbsafes lightweight barrier material
• Up to 30% lighter than the previous version. Leads to easier product handling during installations
• Recommended cash rating is £10,000 (Grade I) or £17,500 (Grade II)
• Tested and certified by the ECB•S to European Standard EN 1143-2 D in Grades DI II
• Deposit feature allows multiple users to constantly deposit cash and valuables securely whilst the
main body of the safe remains locked
• Deposit drawer equipped with an anti-fishing device to prevent anyone removing the contents of the
safe through the drawer
• Supplied with a high security EN 1300 approved class A key lock
• Available in four sizes in Grade I or II
• Grade III available in sizes 110, 150 and 200. POA

Internal Delivery
Model Volume Locking Base Fixing
Height Width Depth* Height Height* Width Depth (kg) Supplied Rating Price
(litres) Price
Grade I Size 60 687 500 521 587 314 400 360 45 144 Key Lock Empty £10,000 £2,359 £225

Size 110 847 600 561 747 474 500 386 91 203 Key Lock Empty £10,000 £2,801 £241



Grade II Size 60 687 500 521 587 314 400 360 45 329 Key Lock Empty £17,500 £2,928 £237




* Projection of handle is 65mm Maximum Deposit size for Size 60 is 30 x 330 x 220 (mm) Height* and litres* shown are usable heights and volumes below anti-fishing devices
Maximum Deposit size for Sizes 110, 150, 200 is 30 x 430 x 220 (mm)

Additional Mechanical Two Key and Two Key and
Lock Electronic
Cut Key Combination Key Locks Combination Combinations Electronic

All Grades* All sizes £59 £141 £155 £237 £333 £265 £346

* Dual locking not available on Grade ll size 60


Fire 017 Fire 017
NT NT

60 12
m in ute
s 0 m in utes

Profile NT
60 or 120 minutes document protection

Model above is
Key Features Profile 4DR

• Highly reliable document protection using modern materials and technology
• Tested and certified to NT Fire 017 – 60 Paper or NT Fire 017 – 120 Paper
• Fire resistance of up to 120 minutes
• Each drawer is protected from fire. Even if one of the drawers is accidently left open,
the other closed drawers are still protected by the built in fire resistant partitions
• Designed to accommodate foolscap or A4 filing

Delivery
External dimensions (mm Internal dimensions (mm) Volume Weight Fire Rating Retail
Model Position
Height Width Depth Height Width Depth (litres) (kg) (mins) Price
Price
Profile 1HR 2DR 734 544 776 291 387 619 139 139 60 £969 £115

Profile 1HR 4DR 1408 544 776 291 387 619 278 230 60 £1,597 £157

Delivery
External dimensions (mm) Internal dimensions (mm)* Volume Weight Fire Rating Retail
Model Position
Price
Profile 2HR 2DR 734 544 776 291 387 619 139 172 120 £1,141 £115

Profile 2HR 3DR 1071 544 776 291 387 619 208 229 120 £1,368 £149

Profile 2HR 4DR 1408 544 776 291 387 619 278 287 120 £1,825 £191

* Each drawer’s internal dimensions
FRE – Fire Resistant Equipment


NEW EN 1300

Archive Cabinet
£1,000 recommended cash rating

Key Features
Model shown is
• Archive Cabinet has a steel, double-wall construction insulated with special fire-resistant barrier material. Size 325

• Available in four sizes with a generous storage capacity ranging from 325–880 litres. Sizes 640 and 880 available as
double door versions
• Secured by three-way boltwork, locking at the top, bottom and side of the door.
• Class A (EN 1300) key lock fitted as standard.
• Can be customised with a range of fittings (eg.lockable compartments, pull-out frames)
• Anchor points in the base allow the cabinet to be fixed to the floor.
• cabinets have a light-grey, powder-coated finish, suitable for any office space.
All

Fittings Delivery
Model (Supplied) Position
Shelf Price
Size 325 1500 700 550 1290 594 430 325 95 3 £1,000 £831 £115

Size 450 1950 700 550 1780 594 430 450 120 4 £1,000 £983 £115

Size 640 1950 950 550 1780 844 430 640 150 4 £1,000 £1,296 £138

Size 880 1950 1260 550 1780 1154 430 880 200 4 £1,000 £1,641 £177


Fitting Shelf Pull-out Frame Lockable Compartment

Size 325 £52 £147 £252

Size 450 £52 £147 £252

Size 640 £68 £175 £320

Size 880 £85 £180 £421


NEW Fire 017 2 Class 35
NT L7
U

0

60 s
m in ute 1 hour

Executive
£1,000 recommended cash rating, 60 minutes document protection

Model shown is
Key Features Size 40

• Compact fire safe designed to protect valuable documents (eg. passports, receipts and
insurance documents)
• Tested and certified to UL72 Class 350 and NT Fire 017-60 Paper offering 60 minutes fire
protection
• Secured by either a key lock or user-friendly programmable electronic lock
• sizes come with internal fittings as standard – see table below
All
• Anchoring points in base allow safe to be fixed to the floor

Drop off Delivery
External dimensions (mm) Internal dimensions (mm) Volume Weight Fire Rating Retail
Model Delivery Position
Price* Price
Key Lock

Size 15 296 390 320 216 310 215 14 27 60 £146 £21 £115

Size 25 342 480 480 245 325 320 25 42 60 £179 £58 £115

Size 40 519 410 445 415 305 320 41 60 60 £202 £58 £115

Size 65 680 555 508 515 385 335 67 130 60 £536 £58 £115

Electronic Lock

Size 15 296 390 320 216 310 215 14 27 60 £191 £21 £115

Size 25 342 480 480 245 325 320 25 42 60 £224 £58 £115

Size 40 519 410 445 415 305 320 41 60 60 £260 £58 £115

Size 65 680 555 508 515 385 335 67 130 60 £605 £58 £115


Fittings Supplied Tray Shelf Lockable drawer

Size 15 1 – –

Size 25 1 – –

Size 40 1 1 –

Size 65 – 1 1


NEW Fire 017
NT

12
0 m in utes

Office
£1,500 recommended cash rating, 120 minutes document protection

Model shown is
Key Features Size 225

• Fire-resistant safe designed to protect documents from fire and theft
• Ideal for offices and small businesses
• Tested and certified in accordance with NT Fire 017-120 Paper. Offering 120 minutes fire protection
• Secured by a user friendly programmable electronic lock
• Supplied with removable shelves as standard
• Available in seven sizes

Fittings Delivery
External dimensions (mm) Internal dimensions (mm) Volume Weight Fire Rating Retail
Model (Supplied) Position
Height Width Depth* Height Width Depth (litres) (kg) (mins) Price
Shelf Price
Size 115 795 580 510 638 426 426 116 160 1 120 £668 £137

Size 125 995 590 510 833 426 346 123 210 2 120 £826 £152

Size 225 1175 650 635 1012 483 463 226 295 2 120 £1,056 £170

Size 300 1285 745 635 1123 578 463 301 340 2 120 £1,351 £183

Size 385 1615 745 635 1438 578 463 385 390 3 120 £1,670 £263

Size 450 1680 840 635 1438 673 463 448 470 3 120 £2,017 £324

Size 785 1695 1206 654 1536 1047 487 783 670 3 120 £3,524 £403




Fire 017 EN 1300
NT

12
0 m in utes

Record Protection Cabinet
120 minutes document protection, up to £1,500 cash rating

Key Features
Model shown is
• Quality document protection using high specification materials Size 30-2

• Tested to NT Fire 017 – 120 Paper
• Fire resistance of 120 minutes
• Can be customised by using fixed shelves, filing rails and lockable cupboards

Internal Fittings Delivery
External dimensions (mm) Internal dimensions (mm) Weight Fire Rating Retail
Model Volume Locking (Supplied) Position
Height Width Depth* Height Width Depth (kg) (mins) Price
(litres) Shelf Price
Size 12-2 859 759 549 700 600 382 160 235 Key Lock 1 120 £1,711 £202

Size 18-2 1209 759 549 1050 600 382 240 313 Key Lock 2 120 £2,054 £231

Size 24-2 1559 759 549 1400 600 382 321 391 Key Lock 3 120 £2,510 £264

Size 30-2 1909 759 549 1750 600 382 401 470 Key Lock 4 120 £2,966 £324

* Projection of handle is 65mm. Depth of hinge is not included in these measurements

Fitting Shelf Pull-out File Frame Lockable Cupboard

Size 12-2 £23 £100 £104

Size 18-2 £23 £100 £104

Size 24-2 £23 £100 £104

Size 30-2 £23 £100 £104


NEW Fire 017
NT

12 s
0 m in ute

DataGuard NT
120 minutes data media protection

Key Features
• Certified NT Fire 017 – 120 Diskette for two-hour protection of data media from fire
Model shown is
• Single-door safe with no insert required – means internal capacity is maximised and up to 80
60% more storage space than other safes in the same class
• User-friendly, slam-action door, which when shut provides full fire protection without
needing to be locked
• Fittings supplied as standard – see table below for details
• Available in four sizes, ranging from 30–128 litres

Internal Fittings Delivery
Model Volume Position
Height1 Width Depth1 Height2 Width2 Depth (kg) Shelf Drawer (mins) Price
(litres) Price
Key Lock

25 530 546 566 280 346 306 30 145 1 0 120 £936 £115

40 700 546 566 450 346 306 48 190 1 1 120 £1,291 £177

80 1025 546 590 775 346 330 89 263 1 2 120 £1,516 £202

120 1025 702 590 775 502 330 128 330 1 2 120 £1,981 £231

Electronic Lock

25 530 546 566 280 346 306 30 145 1 0 120 £1,036 £115

40 700 546 566 450 346 306 48 190 1 1 120 £1,391 £177

80 1025 546 590 775 346 330 89 263 1 2 120 £1,616 £202

120 1025 702 590 775 502 330 128 330 1 2 120 £2,081 £231
1
External heights and depths include plinth and handle projection
2
Internal heights and widths are also equal to the clear opening measurements

Additional Fitting Shelf Drawer

25 £34 £115

40 £34 £115

80 £35 £135

120 £45 £159


14450 1047-1 2 Class 12
EN EN L7
U

5

12 s
S2 0 m in ute 2 h o u rs

DataPlus
£4,000 Cash rating, 120 minutes data media protection
Model above is
Size 5

Key Features
• Quality media protection using high specification materials
• Tested to highest international standards EN 1047-1, UL72 Class 125 and EN 14450 S2
• Fire resistance of 120 minutes
• Can be customised by using fixed shelves, pull out drawers and lockable cupboards
• Electronic and mechanical combination locks available
• Available in five sizes

Internal Delivery
Model Volume Locking Cash Rating Position
Height Width Depth* Height Width Depth (kg) (mins) Price
(litres) Price
Size 1 911 746 780 565 490 400 111 315 Key Lock £4,000 120 £3,301 £224

Size 2 1191 746 780 845 490 400 167 390 Key Lock £4,000 120 £4,065 £239

Size 3 1471 746 780 1125 490 400 221 490 Key Lock £4,000 120 £4,925 £250

Size 4 1941 746 780 1595 490 400 313 640 Key Lock £4,000 120 £6,121 £403

Size 5 1941 1036 830 1570 780 450 556 860 Key Lock £4,000 120 £7,619 £447

* Handle projection is 65mm

Extensible shelf with
Fitting Fixed shelf Lockable cupboard
adjustable dividers

Size 1 £36 £125 £216

Size 2 £36 £125 £216

Size 3 £36 £125 £216

Size 4 £36 £125 £216

Size 5 £57 £173 £249


2 Standard Quality Door
Protection of high value assets

Key Features
• Optimum protection for medium risks
• Consists of a door frame and the main standard quality door
• Supplied with one double bitted key lock and one keyless combination lock as standard
• Achieves high level of protection. Incorporates seven 32mm thick bolts and two glass relockers
(Protected by Tungsten Carbide Pin Anti-drill Plates)
• Finished in a contemporary grey primer
• Grille gate option is available (supplied at an additional cost)

Delivery
Door Weight Total thickness Clear Opening External Dimensions Retail
Model Number of bolts Installation
(Kg) of door (mm) H x W (mm) H x W (mm) Price
Price
2 Standard Quality Door 7 640 165 1920 x 814 2110 x 1273 POA POA

High Value Asset Protection


Centurion Vault

Key Features
• Optimum protection for high value assets
• Consists of modular panels which are assembled together using a welded or bolted method of construction
• Tested and certified by the ECB•S to the latest security standard, EN 1143-1
• Can be integrated into various environments (for example new buildings, existing buildings and to strengthen strong room units)
• Can be designed on a bespoke basis, to suit any shape or size, subject to a full and comprehensive site survey
• Available in a range of security grades

Max span (clearance)
Weight for a permissible ceiling load of Delivery
Wall thickness Retail
Grade per m2 wall, floor, ceiling Installation
(mm) Price
(Kg) 100 kp/m2 500 kp/m2 Price

Euro V 85 300 3350 3350 POA POA

Euro VI 85 300 3350 3350 POA POA

Euro VII 85 300 3350 3350 POA POA

Euro V 100 360 4000 4000 POA POA

Euro VI 100 360 4000 4000 POA POA

Euro VII 100 360 4000 4000 POA POA

Euro VIII 100 360 4000 4000 POA POA

Euro IX 125 440 5250 4750 POA POA

Euro IX CD 125 440 5250 4750 POA POA

Euro X 150 520 5200 5000 POA POA

Euro X CD 150 520 5200 5000 POA POA

Euro XI 220 730 5060 5060 POA POA

Euro XI CD 220 730 5060 5060 POA POA

Euro XII 280 920 4960 4960 POA POA

Euro XII CD 280 920 4960 4960 POA POA


Centurion Door

Key Features
• Optimum protection for high value assets
• Consists of a door frame, grille gate and the main strong room door
• Tested and certified by the ECB•S to the latest security standard, EN 1143-1
• Supplied with one key lock and one mechanical combination lock (up to grade Euro XCD) as standard.
One key lock and two mechanical combination locks on Grades Xl and Xll
• Can be customised with locking and alarm options to meet your specific security needs
• Available in a range of security grades

Delivery
Total Weight Frame Depth Clear opening Retail
Grade Number of bolts Installation
(Kg) (mm) H x W (mm) Price
Price
Euro V 6 1500 230 1970 x 900 POA POA

Euro VI 6 1500 230 1970 x 900 POA POA

Euro VII 6 1500 230 1970 x 900 POA POA

Euro VIII 6 1700 290 1970 x 900 POA POA

Euro IX 6 1700 290 1970 x 900 POA POA

Euro IX CD 6 1700 290 1970 x 900 POA POA

Euro X 6 3000 415 1970 x 900 POA POA

Euro X CD 6 3000 415 1970 x 900 POA POA

Euro XI 6 3000 415 1970 x 900 POA POA

Euro XI CD 6 3000 415 1970 x 900 POA POA

Euro XII 10 3500 415 1970 x 900 POA POA

Euro XII CD 10 3500 415 1970 x 900 POA POA


Safe Deposit Lockers

Key Features
• Dual control locking mechanism
Each locker is fitted with a dual control lock with two keyholes. One key is for the renter and the other
is for the guardian. The guardian key is common to every locker in the installation. The lock is designed
to make it impossible for the renter to remove his/her key without first closing and locking the door

• Inner containers
All lockers are supplied with a lockable inner container. These are supplied with a hasp and staple to
accept the renter’s own padlock

• Numbering
Within each group of lockers, the numbers start at the top left corner and run horizontally in rows to
the bottom right corner. Other numbering systems can also be accommodated

• Total security
Safe deposit lockers can be integrated into a vault room which is secured by a vault door for extra
security

• Locker groups
A locker group is available in two sizes (8 or 10 module). Within this group, a number of arrangements
can be created dependant upon the size of the deposit boxes. Please note, the arrangements are not
fixed and Gunnebo can create an arrangement to meet your specific security requirements

External section Delivery
Retail
Safe Deposit Lockers dimensions (mm) Installation
Price
Height Width Depth Price

8 module

Module 521 813 600 POA POA

Cornice 51 813 600 POA POA

Separator Pullout Shelf 25 813 600 POA POA

Plinth 89 813 600 POA POA

10 module

Module 521 813 600 POA POA

Cornice 51 813 600 POA POA

Separator Pullout Shelf 25 813 600 POA POA

Plinth 89 813 600 POA POA


Notes

Notes


...the premier underfloor safe brand

Churchill Safes are recognised as the leading brand for underfloor safes.
Such success is based upon understanding the security market and
meeting customer needs. This commitment and initiative is reflected in
the Churchill Safes product range. Products vary from a small wall safe
to high security underfloor safes. Such a comprehensive range means that
finding an underfloor solution is a simple process.

NEW

Magpie Wall Safe
£1,000 cash rating

Model shown is
Key Features M5

• Wall safe designed to protect cash and valuables
• Construction includes a 10mm door 6mm outer frame
• Equipped with a double bitted key lock as standard
• Can be customised with combination or digital locking option
• Sizes 4 and 5 supplied with shelf

Fittings
Door (mm) External dimensions (mm) Weight Cash Retail Delivery
Model Locking (Supplied)
Height Width Height Width Depth* (kg) Rating Price Price
Shelf
M2 127 178 140 229 121 9 Key Lock N/A £1,000 £181 £21

M3 210 178 229 229 121 12 Key Lock N/A £1,000 £216 £21

M4 293 178 306 229 165 18 Key Lock 1 £1,000 £277 £21

M5 369 240 381 305 165 27 Key Lock 1 £1,000 £328 £21

*Please add 30mm for dial projection

Additional Mechanical
Model Electronic
Cut Key Combination

All models £32 £141 £181
Wall Safe


P SELLER S Class 1
TO Vd

Domestic
£4,000 cash rating
Model above is
D3L
Key Features
• Traditional underfloor safe which protects cash and valuables
• Recommended cash rating of up to £4,000
• Easy upgrade option: can be upgraded to £6,000 (by using the Vector door)
• Construction includes a 30mm thick door coated in a unique and
environmentally friendly coating
• Secured by a double bitted key lock (VdS class 1) as standard
• Unique spring loaded escutcheon
• Can be customised with combination or electronic locking option
• Available in three models
• Deposit facility available – supplied with 12 capsules
• Supplied with full installation instructions

External dimensions (mm) Internal dimensions (mm) Safe Opening Weight Cash Retail Delivery
Model Locking
Height* Width Depth Height Width Depth (mm) (kg) Rating Price Price
D2L 375 240 240 229 215 215 140 14.5 Key Lock £4,000 £294 £21
D3L 455 315 315 305 290 290 140 24.5 Key Lock £4,000 £328 £21
D4L Deposit 455 315 315 305 290 290 140 26.5 Key Lock £4,000 £421 £21

* External height includes a 125mm neck

Model Electronic
Cut Key Combination
All models £35 £141 £333
Underfloor Safes


S Class 1
Vd

Vector
£6,000 cash rating
Model above is
V3

Key Features
• Traditional underfloor safe which protects cash and valuables
• Construction includes a 45mm thick door coated in a unique and environmentally friendly coating
• Secured with a double bitted key lock (VdS class 1) as standard
• Available in three models

Safe
External dimensions (mm) Internal dimensions (mm) Weight Cash Retail Delivery
Model Opening Locking
Height* Width Depth Height Width Depth (kg) Rating Price Price
(mm)
V2 375 240 240 229 215 215 140 16 Key Lock £6,000 £512 £21

V3 455 315 315 305 290 290 140 26 Key Lock £6,000 £568 £21

V4 Deposit 455 315 315 305 290 290 140 28 Key Lock £6,000 £637 £21


Model Electronic
Cut Key Combination

All models £35 £141 £333
Underfloor Safes


S Class 1
Vd

Bulldog 400
Model above is
CBS12
£6,000 cash rating

Key Features
• Large capacity square door underfloor safe which protects cash and valuables
• Supplied with an air pump assisted door for easy lift
• Available in two models

Safe
Door External dimensions (mm) Internal dimensions (mm) Weight Cash Retail Delivery
(mm) Height * Width Depth Height Width Depth (kg) Rating Price Price
(mm)
CBS11 356 x 255 425 490 350 255 458 330 240 x 300 45 Key Lock £6,000 £799 £58

CBS12 356 x 255 590 490 350 420 458 330 240 x 300 50 Key Lock £6,000 £879 £58

* External height includes 150mm neck

Model Electronic
Cut Key Combination

All models £35 £141 £333

Underfloor Safes


S Class 1
Vd

Sapphire

Key Features
Model above is
• Recommended cash rating of £10,000 ES4 Deposit
• Easy upgrade options: can be upgraded to £17,500 recommended cash rating by using a Ruby door
• The door is constructed from stainless steel protecting the contents from thermal and mechanical attack
• All deposit versions include a lockable deposit cap
• Available in 2 models
• Supplied with reinforcing mesh and full installation instructions

Safe
(mm)
ES3 470 300 300 300 290 290 140 27 Key Lock £10,000 £787 £21

ES4 Deposit 470 300 300 300 290 290 140 27 Key Lock £10,000 £941 £21


Model Electronic
Cut Key Combination

All models £35 £141 £333
Underfloor Safes


S Class 1
Vd

Ruby

Model above is
Key Features ER14 Deposit

• Underfloor safe which protects cash and valuables
• The door is constructed from stainless steel protecting the contents from thermal and mechanical attack

Safe
(mm)
ER13 470 300 300 300 290 290 140 29 Key Lock £17,500 £1,366 £21

ER14 Deposit 470 300 300 300 290 290 140 29 Key Lock £17,500 £1,478 £21


Model Electronic
Cut Key Combination

All models £35 £141 £333
Underfloor Safes


P SELLER S Class 2
TO Vd

Emerald
£35,000 recommended cash rating Model above is
EE24D

Key Features
• Underfloor safe which protects cash and valuables
• The door is constructed from solid stainless steel 45mm thick
protecting the contents from thermal and mechanical attack

Safe
(mm)
EE23 560 300 300 300 290 290 140 32 Key Lock £35,000 £1,625 £58

EE24 Deposit 560 300 300 300 290 290 140 32 Key Lock £35,000 £1,749 £58


Additional
Model Electronic
Cut Key

All models £35 £333
Underfloor Safes


Notes

Notes


...the premier document protection brand

For every business protection of documentation is of paramount importance. Losing this
invaluable information can lead to a disastrous impact on the business.
Common outcomes include the loss of clients and a decline in capacity to attain new business.
With the Rosengrens product range you are sure to find a flexible and secure solution.
Combining unique design and innovative features, each safe or cabinet ensures that your
documents are securely protected to the highest standards.

1143-1
EN

Gr
a d e II − I V

Atlantic
Up to £60,000 cash rating (Grade II, III, IV)

Model above is
Size 120W
Key Features
• Lightweight cash safe
• Recommended cash rating of up to £60,000 (Grade lV)
• Tested and certified by the ECB•S to the European standard EN 1143-1
• Alternative locking includes the electronic or dual locking option
• Manufactured to ISO 9001:2008 accredited quality controlled process
• Can be customised with a wide range of fitting options
• A comprehensive range of sizes available
• Special “W” version is suitable for storage of till drawers

Delivery
External dimensions (mm) Internal dimensions (mm) Weight Volume Fittings Cash Retail
Model Locking Base Fixing
Height Width Depth* Height Width Depth (kg) (litres) Supplied Rating Price
Price
Grade II Size 40 495 555 400 405 460 230 182 43 Empty Key Lock £17,500 £1,834 £221

Size 52 615 555 490 525 460 320 251 77 Empty Key Lock £17,500 £2,102 £245


Size 70W 790 655 571 700 560 401 415 157 Empty Key Lock £17,500 £2,614 £263



Grade III Size 52 615 555 490 525 460 320 267 77 Empty Key Lock £35,000 £2,967 £250

BRE– Burglary Resistant Equipment





Grade IV Size 72 815 555 490 725 460 320 395 107 Empty Two Key Locks £60,000 £5,460 £309

Size 70W 790 655 571 700 560 401 525 157 Empty Two Key Locks £60,000 £6,595 £348






Mechanical Two Key and Key and
Lock Electronic
Combination Key Locks Combination Electronic

All Grades All sizes £141 £155 £237 £333 £346

Cupboard Cupboard Cupboard
Fitting Shelf
(200mm int.height) (300mm int.height) (400mm int.height)

All Grades Size 40 £25 N/A N/A N/A

Size 52 £25 N/A £306 N/A

Size 72 £25 N/A £306 N/A

Size 70W £28 £284 N/A N/A

Size 104W £28 £284 N/A N/A

Size 120W £28 £293 N/A £366

Size 150W £87 N/A N/A £437

BRE– Burglary Resistant Equipment


1047-1
EN

12
0 m in utes

Sargasso
120 minutes document protection Model above is
P177

Key Features
• Optimum solution for the protection of documents
• Tested and certified by the ECB•S to the European standard EN 1047-1 Class S 120 P
Offering 120 minutes fire protection for paper documents
• Secured by key lock as standard. Can be equipped with electronic or dual locking as an option
• Can be customised with a wide range of fittings (e.g. fixed shelf, lockable cupboard)
• Available in two sizes

Fire Delivery
External dimensions (mm) Internal dimensions (mm) Weight Volume No. of Lever Fittings Retail
Model Locking Rating Position
Height Width Depth* Height Width Depth (kg) (litres) Arch Files** Supplied Price
(mins) Price
P120 1403 890 664 1203 733 434 458 383 Key Lock 30 Empty 120 £3,770 £207

P177 1970 1250 664 1770 1093 434 801 840 Key Lock 75 Empty 120 £6,005 £389

* Projection of handle is 50mm ** Lever Arch width 75mm

Lock Two Key Locks Combination Electronic

All sizes £155 £141 £333

Fitting Fixed Shelf Extensible Shelf Extensible A4 File Frame Lockable Cupboard Data Insert

P120 £36 £109 £174 £301 £968

P177 £42 £146 £278 £570 £968


2000C Safe Deposit Lockers

Key Features
• Dual control locking mechanism
Each locker is secured by client lock 32A81S, second lock custodian controlled.
Can be upgraded to RBM system – box management system

• nner containers
I
All lockers are supplied with an inner container

• umbering
N
Numbering as per customer’s requirements

• otal Security
T
Safe deposit lockers can be integrated into a vault room which is secured by a vault door for
extra security. Manufactured to ISO 9001 accredited quality controlled process

• ocker Groups
L
Locker columns available in three heights.
All can be arranged with various locker sizes from 50mm to 600mm

• inish
F
Available in various colours.


For further information please contact the Gunnebo sales department on 01902 455111.


Terms Conditions

Preamble 10. Gunnebo will conform to the Customer’s site induction agreed on how the variations will affect the Contract
procedures. Should this be required to take place prior to Sum, the time for completion and other terms of the
1. Our Terms Conditions shall apply in all instances. commencement, Gunnebo reserve the right to charge for Contract, or the dispute has been settled through
Gunnebo reserves the right, at any time, to modify, this provision. Adjudication or Arbitration.
alter, or update the terms of use, product prices and
product information and you agree to be bound by such 11. Gunnebo operatives will be provided with a project 23. If completion of the Works is delayed as a result of
modifications, alterations, or updates on subsequent specific method statement and risk assessments disagreement between the parties on the consequences
visits. Your placement of an order indicates your pertinent to the environment that they will face. of variations, the Customer shall pay any part of the
acceptance of these terms and conditions. Contract Price which would have become due if the
12. The Customer shall provide welfare facilities free of Works had not been delayed.
Definitions charge for the use of Gunnebo operatives, available from
the date of commencement and throughout the duration Commissioning
2. F
or the avoidance of doubt, the following expressions of the Works.
shall (unless the context otherwise admits) have the 24. Where specifically requested at the moment of enquiry,
following meanings: 13. The Delivery Period shall commence once Gunnebo are commissioning tests shall be carried out to determine
in receipt of all pertinent information. The duration of whether the equipment is fit for purpose.
i. “Contract” shall mean the written agreement between this period will be governed by capacity in production and
the two parties concerning performance of the completeness of information received. 25. The Customer shall provide free of charge any power,
Works, encompassing the tender enquiry, subsequent lubricants, water, fuel, raw materials and other materials
submission and agreement of any pricing considerations 14. The date of commencement will be determined by the or equipment to enable such tests.
made therein; duration of the Delivery Period. Should information
ii. “Contract Sum” shall mean the value of Gunnebo’s works, prove to be incomplete, Gunnebo shall identify the 26. Any such tests shall be carried out during normal working
based upon Gunnebo’s tender submission, subject to any remedial action required by the Customer. Gunnebo hours, conducted in accordance with general practice in
variances, to be ascertained and paid in accordance with may endeavour to furnish the Customer with the appropriate branch of industry.
the provisions hereinafter; indicative timescales, but will not commit to a date
iii. “Customer” shall mean the party to whom Gunnebo are of commencement until all outstanding matters are 27. If the commissioning tests show the Works not to be
directly contracted; an end user Client, Main Contractor resolved. in accordance with the Contract, Gunnebo will within
or Sub-Contractor; a determined and reasonable period remedy any
iv. “Gunnebo” shall mean Gunnebo UK Ltd or their 15. Due to the manner with which Gunnebo commencement deficiencies.
designated representatives; is determined, Gunnebo shall not be held liable for any
v. “Works” shall mean the equipment and resources conflict between the date of commencement and any 28. The Customer is not entitled to use the Works or any
necessary to enable the completion of the Contract; target of the Customer. part thereof before commissioning. If the Customer does
vi. “Equipment” shall mean all materials pertinent to so without Gunnebo’s consent In Writing, he shall be
the tender submission, subject to any variances, and Impact on Commencement or Continuity deemed to have taken over the Works. Gunnebo shall
necessary plant, solely for our use, to facilitate the Works; then be relieved of their duty to carry out such tests.
vii. “Delivery Period” shall mean the length of time required 16. If the Customer anticipates that the fulfilment of their
to facilitate design and manufacture of equipment obligations will delay the completion of the Works; Completion
necessary for the completion of the Works; whether this manifests as a delay to commencement
viii. “Site” shall mean the place where the Works are to take or leads to Gunnebo’s progress being hampered; the 29. The Works shall be considered complete when either
place, including an allowance of space for any necessary Customer shall notify Gunnebo In Writing, stating the the commissioning has proved equipment to be fit
unloading, safe storage and consideration for efficient reason and, if possible, the time when they will be able for purpose or the Client has begun making use of
transportation of equipment; to comply with their obligations. The amount of time equipment.
ix. “In Writing” shall mean communication by document permitted to Gunnebo for the completion of the Works
signed by the parties, or by letter, facsimile, and electronic shall be automatically extended accordingly. Gunnebo 30. If Gunnebo anticipates that they will not be able to
mail; shall endeavour to provide timely advice as to the impact comply with their obligations within the times specified
x. “Gross Negligence” shall mean an act or omission upon duration and cost, and seek amendment of the in the Contract, they shall forthwith notify the Customer
implying a failure to pay due regard to serious Contract Sum, where applicable. thereof In Writing, stating the reason, and, if possible,
consequences, which a conscientious party would when compliance can be expected. If Gunnebo fails
normally foresee as likely to ensue. 17. Without prejudice to Gunnebo’s rights elsewhere in this to give such notice, the Customer shall be entitled to
document, if the Customer fails to fulfil, correctly and compensation for certain additional costs which will be
Product Information timely, his obligations necessary for completion of the incurred and which could have been avoided had such
Works, the following remedies shall apply: notice been received.
3. All information and data generated during the tender
process are binding only to the extent that they are by i. If the equipment has not been delivered to Site, Gunnebo 31. Should there be no reasonable entitlement to an
reference expressly included in the Contract. shall arrange for temporary storage at the Customer’s extension of time great enough to accommodate for
risk and cost; the eventual completion date of the Works; Gunnebo’s
Intellectual Property ii. The element of the Works completed shall be valued delay entitles the Customer to liquidated and ascertained
accordingly and the Customer shall pay any part of the damages from the date at which completion should have
4. All drawings and technical information relating to the Contract Sum which, but for such delay, would have occurred. Liquidated and ascertained damages shall not
Works shall remain the property of the submitting become due; exceed 1% of the Contract Sum per week and are capped
party. Drawings and technical information received by iii. Gunnebo may suspend in whole or in part his at a maximum of 10% of the Contract Sum, calculated
one party shall not, without the consent of the other performance of the Contract. Notice to the Customer on a pro-rata basis against the Works. All other claims
party, be used for any other purpose than that for which shall be raised forthwith In Writing; for compensation against Gunnebo based on such delay
they were provided. They may not, without the consent iv. The Customer shall reimburse Gunnebo for any costs shall be excluded, except where Gunnebo has been guilty
of the submitting party, otherwise be used or copied, which are reasonably incurred as a result of measures of Gross Negligence.
reproduced, transmitted or communicated to a third undertaken to mitigate the situation.
party. 32. The liquidated and ascertained damages become due
18. Should the Customer’s inability to fulfil their obligations at the Customer’s request In Writing but not before
5. Where, under a separate contract, it is a contractual not be attributable to Force Majeure, Gunnebo may, by commissioning or termination of the Contract.
requirement of the Customer’s to provide their customer notice In Writing, require the Customer to remedy the
with an Operational and Maintenance Manual, Gunnebo default within a determined and reasonable period. 33. If Gunnebo’s delay is such that the Customer has become
reserve the right to charge for this service. If, for any reason, the Customer fails to remedy the entitled to the maximum level of damages and the Works
default within such period, Gunnebo may, by notice In are still not completed, the Customer may demand In
Quality Assurance Writing, terminate its employment under the Contract. Writing completion within a final reasonable period
Gunnebo shall then be entitled to compensation for the which shall not in any event be less than one week. If
6. Should the need arise for either the Customer to inspect losses incurred as a result of the Customer’s default. The Gunnebo does not complete the Works within such final
equipment prior to dispatch, a request In Writing compensation shall not exceed the Contract Sum. period and this is not due to any circumstance for which
would be necessary a minimum of 72 hours before any the Customer is responsible, then the Customer may
proposed visit. Unless otherwise agreed, any inspection Variations by notice In Writing to Gunnebo terminate Gunnebo’s
would be at the place of manufacture, during normal employment under the Contract.
working hours. Any tests undertaken will be carried out 19. During the currency of the Contract and subject to
in accordance with general practice in the appropriate provisions elsewhere in this document, Gunnebo will act 34. It shall be a condition precedent to the Customer’s right
branch of industry concerned in the country of upon requests In Writing from the Customer, to vary the to liquidated and ascertained damages that he shall
manufacture. All costs associated with an inspection visit scope, design and construction of the Works. lodge a claim In Writing for such damages within three
are to be borne solely by the Customer. months after the time when completion should have
20. To minimise impact upon the overall duration of the taken place.
7. Records of Quality Inspections are maintained by Works, the Customer shall ensure that any request
Gunnebo and can be provided, on receipt of a request In contains an exact description of the variation required. 35. Gunnebo shall be entitled to an extension of the time for
Writing. completion if delay occurs:
21. As soon as possible after receipt of a request for a
Preparatory Work variation, Gunnebo shall notify the Customer In Writing i. because of any of the circumstances covered under the
whether it is possible to conform with the request. heading Force Majeure;
8. Gunnebo will provide information in good time, detailing Should the request fall within Gunnebo‘s sphere of ii. as a result of variation to the Works;
the manner in which equipment will be installed and expertise, then Gunnebo shall advise In Writing the value iii. as a result of suspension of the Works;
offer the Customer advice to aid their preparation of such work and the extent of the impact upon the iv. by an act or omission on the part of the Customer;
of suitable foundations, access requirements and overall duration of the Works, assuming continuity can v. by an act or omission on the part of another trade
interfacing with others, where necessary. be achieved. The amount of time permitted to Gunnebo engaged on the same project.
for the completion of the Works shall be automatically
9. The Customer shall recognise the limitations of extended accordingly, with the Contract Sum amended, 36. The extension of time shall be reasonable having regard
Gunnebo’s responsibilities and ensure that all preparatory as applicable. to all the circumstances. This provision applies regardless
work outside of Gunnebo’s remit is completed in time for of whether the reason for the delay occurs before or after
the commencement of the Works. 22. Gunnebo shall not be obliged to carry out variations the agreed time for completion.
required by the Customer until either the parties have


Payment obligations, the Customer may, by notice In Writing, fix Severability
a final time for completion of Gunnebo’s obligations. If
37. Subject to a demonstrable level of credit worthiness, and Gunnebo fails to fulfil his obligations within such final 60. If any condition, clause or provision of these General
unless otherwise agreed, payment shall be made within time, the Customer may himself undertake or employ a Terms Conditions is held to be illegal or unenforceable,
30 days from the date of the invoice. third party to undertake necessary remedial works at the it may be severed and the validity or enforceability of the
risk and expense of Gunnebo. Where successful remedial remainder of these General Terms Conditions shall not
38. Each invoice will identify the percentage of equipment on works have been undertaken by the Customer or a third be affected thereby.
site and installed in relation to the Contract Sum. party, reimbursement by Gunnebo of reasonable costs
incurred by the Customer shall be in full settlement of Third Party Rights
39. Should the installation be delayed due to a cause for Gunnebo’s liabilities for the said defect.
which the responsibility rests with the Customer or any 61. Notwithstanding any other provision of these General
of their contractors other than Gunnebo, the Customer 51. Where the defect has not been successfully remedied, Terms Conditions, nothing in these General Terms
shall compensate Gunnebo for: Gunnebo offer either of the following remedies: Conditions confers or purports to confer any right to
enforce any of its terms on any person who is not a party
i. waiting time and time spent on extra journeys; i. The Customer is entitled to a reduction of the Contract to it and the provisions of the Contracts (Rights of Third
ii. costs and extra work resulting from the delay, including Sum in proportion to the reduced value of the Works, Parties) Act 1999 shall be of no effect in respect of the
removing, securing and setting up the installation provided that under no circumstance shall such reduction Agreement.
equipment; exceed 10% of the revised Contract Sum, or;
iii. additional costs, including costs as a result of Gunnebo ii. Where the defect is so substantial as to significantly Construction Industry Scheme
having to keep his plant on Site for a longer time than deprive the Customer of the benefit of the Contract,
expected; the Customer may terminate Gunnebo’s employment 62. Gunnebo shall provide the Customer with its unique
iv. additional costs for journeys and board and lodging for under the Contract by notice In Writing to Gunnebo. The taxpayer reference number and company registration
Gunnebo’s personnel; Customer is then entitled to compensation for the loss number in sufficient time to allow the Customer to verify
v. additional financing costs and costs of insurance; he has suffered up to a maximum of 10% of the Contract Gunnebo’s payment status for the purposes of Chapter
vi. other documented costs incurred by Gunnebo as a result Sum. 3 of Part 3 of the Finance Act 2004 and the Income
of changes in the installation programme. Tax (Construction Industry Scheme) Regulations 2005.
Force Majeure Gunnebo warrants that at the date of this Contract it is
40. Should the installation element be measured on a time registered for gross payment under section 63(2) of the
related basis, all pertinent expense incurred will be 52. Either party shall be entitled to suspend performance of Finance Act 2004 and that it shall remain registered for
incorporated into the Contract Sum. their obligations under the Contract to the extent that gross payment until all payments under this Contract
such performance is impeded or made unreasonably have been made.
41. If the Customer fails to pay by a stipulated date, onerous by any of the following circumstances beyond
Gunnebo shall be entitled to interest from the day on the control of the parties: CDM Regulations
which payment was due. The rate of interest shall be 8%
above the Bank of England base rate at that time when industrial disputes, fire, war, extensive military 63. Gunnebo shall comply with the Health and Safety at
payment was due. In cases of late payment Gunnebo mobilisation, insurrection, requisition, seizure, embargo, Work Act 1974, the Factories Act 1961, the Offices,
may, after having notified the Customer In Writing, restrictions in the use of power. Shops, Railway Premises Act 1963, the Management of
suspend performance of the Contract until payment Health and Safety at Work Regulations 1992 and The
is received. If the Customer has not paid the amount 53. A circumstance referred to in this clause, occurring Construction (Design and Management) Regulations
due within three months, Gunnebo shall be entitled to after the formation of the Contract, shall give a right to 2007 (CDM) and amendments and regulations made
terminate its employment under Contract by notice In suspension only if its effect on the performance of the under or thereto.
Writing and to claim compensation for the loss. Contract could not be reasonably foreseen at the time of
the formation of the Contract. Return Policy
Retention of Title and Transfer of Risk
54. The party claiming to be affected by Force Majeure shall 64. We appreciate that there may well be a time when
42. The equipment shall remain the property of Gunnebo notify the other party In Writing without delay on the a purchase may not prove to be of satisfaction and a
until paid for in full. occurrence of any Force Majeure and on the cessation refund will be sought. Should a customer wish to return
of such circumstance. If Force Majeure prevents the a product from our standard safe range, the following
43. Gunnebo shall be liable for any damage to the equipment Customer from fulfilling his obligations, they shall conditions shall apply:
which occurs before the risk has passed to the Customer. compensate Gunnebo for expenses incurred in securing
This applies irrespective of the cause of the damage, and protecting the Works. • Gunnebo will only accept returns within seven (7) days
unless the damage has been caused by the Customer or of delivery;
anyone for whom he is responsible in connection with 55. Regardless of what might otherwise follow from these • Goods shall be returned to Gunnebo point of dispatch,
performance of the Contract. General Terms and Conditions, either party shall be as identified on the proof of delivery notice and
entitled to terminate the Contract by notice In Writing invoice;
44. Gunnebo shall be liable for damage to the Customer’s to the other party if performance of the Contract is • A re-stocking charge, equal to 25% of the Contract
property occurring before commissioning of the Works suspended under Force Majeure for more than six Sum will apply.
only if it is proved that such damage was caused by months. • Any postage and packing costs incurred on returned
negligence on the part of Gunnebo or anyone for whom items are non-refundable.
we are responsible in connection with the performance Anticipated Non-Performance
of the Contract. Gunnebo shall, however, under no The returned product must be in a condition that can
circumstance be liable for loss of production, loss of profit 56. Notwithstanding other provisions in these General only be described “as new” and securely packaged with
or any other consequential economic loss. Terms and Conditions regarding suspension, each party the original packaging or a suitable alternative of similar
shall be entitled to suspend the performance of their quality;
45. The risk of loss or damage to the equipment shall obligations under the Contract, where it is clear from
pass to the Customer on handover or commissioning the circumstances that the other party will not be able Any and all manuals and accessories must be returned in
of the Works, unless such loss or damage results from to perform his obligations. A party suspending their conjunction with the product.
Gunnebo’s negligence. performance of the Contract shall forthwith notify the
other party thereof In Writing. With the above criteria having been satisfied, a refund
Product Liability will be issued, minus our outgoing delivery cost.
Consequential Loss
46. Gunnebo shall remedy any defect or non-conformity Delivery Installation
in the Works resulting from faulty design, materials or 57. Save as otherwise stated in these General Terms and
workmanship. However, we shall not be liable for loss Conditions there shall be no liability for either party 65. Where ‘Delivery’ is priced in this Selection Guide this
of production, loss of profit or any other consequential towards the other party for loss of production, loss is drop off only and does not include base fixing or
economic loss. of profit, loss of use, loss of contracts or for any other positioning.
consequential or indirect loss whatsoever.
47. Gunnebo’s liability is limited to defects in the Works 66. All products have a separate delivery and position or
which appear within a period of one year from Settlement of Disputes delivery and base fixing price. This price includes delivery
commissioning. If the daily use of the equipment to ground floor or upper floor (via a lift) with clear access.
exceeds that which is agreed, this period shall be reduced 58. In the event that an adjudicator has not been nominated Ground floor is defined as level with pavement and no
proportionately. If commissioning has been delayed for during the formulation of the Contract, any dispute or external steps. Delivery must occur during the working
reasons for which the Customer is responsible, Gunnebo’s difference arising under out of or in connection with day hours of 8.30am – 5.30pm. Delivery outside these
liability for defects shall not be extended beyond 18 these General Terms Conditions may be referred to hours will incur an additional cost (POA). Gunnebo can
months after delivery. adjudication at anytime to an adjudicator nominated by also remove and dispose of your old safe/cabinet after
the president or vice-president for the time being of the delivering your new product (POA).
48. The Customer shall without undue delay notify Gunnebo Chartered Institute of Arbitrators and shall be conducted
In Writing of any defect which appears. Such notice shall in accordance with the Scheme for Construction Delivery location
under no circumstance be given later than two weeks Contracts (England Wales) Regulation 1998 SI No
after the expiry of the period stated previously. The notice 649 or any amendment or re-enactment thereof. The 67. Delivery charges are for within mainland UK. However,
shall contain a description of the defect. If the Customer Adjudicator’s decision shall be final and binding on certain postcodes are considered geographic extremities
fails to notify Gunnebo In Writing of a defect within the the parties until the dispute of difference is finally (Northern Ireland, Isle of Man, Channel Islands, Scottish
set time limit, the right to have the defect remedied is determined either by agreement between the parties or Islands, Scilly Islands).
lost. Where the defect is such that it may cause damage, the courts. Gunnebo can deliver to these locations and outside the
the Customer shall immediately inform Gunnebo In UK at an additional cost.
Writing. The Customer shall bear the risk of damage Governing Law and Jurisdiction
resulting from his failure so to notify. Prices
59. These General Terms Conditions shall be governed by
49. Should no defect be found for which Gunnebo is liable, and construed in all respects in accordance with the laws 68. The full price of your product and delivery will be shown
we shall be entitled to compensation for the costs of England and Wales, and the English Courts shall have on your order acknowledgement.
incurred as a result of acting upon the notice. jurisdiction with regard to all matters arising from these
General Terms Conditions.
50. If, within a reasonable time, Gunnebo does not fulfil our


GUGB.uk.9037.R1

Gunnebo UK Ltd
Fairfax House
Pendeford Business Park
Wobaston Road
Wolverhampton FM 01305
EMS 577165
West Midlands
WV9 5HA
United Kingdom
Phone: +44 (0) 1902 455111
Fax: +44 (0) 1902 351961
marketing.uk@gunnebo.com
www.gunnebo.co.uk

Selection Guide Price List 2013

More Related Content

Similar to Selection Guide Price List 2013 (9)

More from Gunnebo UK (20)

Selection Guide Price List 2013